Terms & Conditions

1. Introduction

These terms and conditions outline the rules and regulations for the use of our home interior services. By accessing or using our services, you agree to be bound by these terms. If you disagree with any part of these terms, please do not use our services.

2. Service Agreement

We provide end-to-end home interior design services, including design consultation, material selection, furniture sourcing, and project execution. The scope of work will be defined in the initial agreement with each client, and any changes or additional work will require mutual agreement and may incur additional charges.

3. Payment Terms

Payments for our services are structured in stages, with specific amounts due upon the completion of various project milestones. The payment structure will be outlined in the project agreement. Failure to make timely payments may result in a delay in project completion or cancellation of the contract.

4. Quote and Pricing

The initial quote provided to you is a tentative cost estimate based on the design and scope of work at the time. Prices listed in the quote may change depending on changes in the design, materials, or scope of work. We will inform you of any changes, and the revised quote will be shared for approval.

5. Cancellation and Refund Policy

If you wish to cancel the project after making an initial payment, the cancellation terms outlined in our contract will apply. Refunds will be processed in accordance with our refund policy, which takes into account the work completed up until the point of cancellation.

6. Project Timeline

We will provide a tentative project timeline during the initial consultation. While we strive to meet deadlines, delays may occur due to unforeseen circumstances. We will communicate any delays and work to complete the project as efficiently as possible.

7. Changes to Design or Scope

Any changes to the agreed-upon design or scope of work after the project has started must be discussed and approved by both parties. Changes may incur additional costs and may affect the overall timeline of the project.

8. Liability

We are committed to delivering high-quality interior design services. However, we are not liable for any damages caused by third-party products or services used in the project. Any issues related to third-party products will be addressed directly with the respective suppliers.

9. Warranty and Post-Completion Support

We offer a warranty on certain aspects of the design and installation, as outlined in the project agreement. After project completion, we also offer post-completion support to address any issues that may arise.

10. Use of Client Information

We take your privacy seriously and will not share your personal information with third parties without your consent. Any personal data collected during the project will be used solely for the purpose of completing the project and enhancing your experience.

11. Governing Law

These terms and conditions are governed by and construed in accordance with the laws of [Your Jurisdiction]. Any disputes arising from these terms will be resolved in the courts of [Your Jurisdiction].

12. Amendments

We reserve the right to update or amend these terms and conditions at any time. Any changes will be communicated to you and will take effect immediately. Continued use of our services after such updates constitutes acceptance of the new terms.